Notice to the Government of delays.

  1. Law
  2. CFR 48
  3. Federal Acquisition Regulations System
  4. Department of Education Acquisition Regulation
  5. Clauses and Forms
  6. Solicitation Provisions and Contract Clauses
  7. Text of Provisions and Clauses
  8. Notice to the Government of delays.

Checkout our iOS App for a better way to browser and research.

3452.242-71 Notice to the Government of delays.

As prescribed in 3442.7002, insert the following clause in all solicitations and contracts other than purchase orders:

Notice to The Government Of Delays (MAR 2011)

The contractor shall notify the contracting officer of any actual or potential situation, including but not limited to labor disputes, that delays or threatens to delay the timely performance of work under this contract. The contractor shall immediately give written notice thereof, including all relevant information.

(End of clause)


Download our app to see the most-to-date content.